[Download] "Frank Hanrahan and Marie Hanrahan v. Audubon Builders" by Superior Court of Pennsylvania # Book PDF Kindle ePub Free
eBook details
- Title: Frank Hanrahan and Marie Hanrahan v. Audubon Builders
- Author : Superior Court of Pennsylvania
- Release Date : January 16, 1992
- Genre: Law,Books,Professional & Technical,
- Pages : * pages
- Size : 77 KB
Description
Audubon Builders, Inc., and both James and Audubon Brink, as individuals, (Appellants) appeal from an order of the Court of Common Pleas directing them to pay an amount of $150 per day for each day from February 15, 1988 to December 22, 1988 in liquidated damages resulting from delays in completion of a construction project at the home of Frank and Marie Hanrahan (Appellees). We vacate and remand in part and affirm in part.
![](http://pinterest.com/pin/create/button/?url=https://ljvsbmynyv.blogspot.com/2021/05/download-frank-hanrahan-and-marie.html&media=https://is4-ssl.mzstatic.com/image/thumb/Publication/v4/b5/7e/c4/b57ec4b7-af95-2715-3396-e68f18fa2590/source/700x700bb.jpg&description=[Download] "Frank Hanrahan and Marie Hanrahan v. Audubon Builders" by Superior Court of Pennsylvania # Book PDF Kindle ePub Free){kind=link}